We welcome article submissions from experts in the areas of coal, mining,
shipping, etc.
To Submit your article please click here.
|
|
|
Friday, 17 July 15
DO CANCELLATION RIGHTS UNDER VOYAGE CHARTERPARTY SURVIVE RE-NOMINATION OF LOAD PORT? - INCE&CO
 KNOWLEDGE TO ELEVATE
Do cancellation rights under voyage charterparty survive re-nomination of load port?
St Shipping & Transport Inc v. Kriti Filoxenia Shipping Co SA [2015] EWHC 997 (Comm) (MT Kriti Filoxenia)
The Commercial Court has considered whether cancellation provisions in the BEEPEEVOY3 charterparty form were applicable in the event of re-nomination of a load port by charterers under the charter. In this case, the Charterers re-nominated the load port which the Owners were not able to reach by the cancellation date. The Charterers cancelled the charterparty. In arbitration proceedings, the Tribunal found that the cancellation provisions were not applicable where the Charterers had exercised the contractual option to re-nominate a load port. The Charterers appealed the decision to the Commercial Court, which upheld the findings of the Tribunal and dismissed the appeal.
The background facts
This case concerned a voyage charterparty under the BEEPEEVOY 3 standard form. The key clauses in the charterparty provided as follows:
“17.… If it appears to Charterers that the Vessel will be delayed beyond the Cancelling Date Charterers may require Owners to notify Charterers of the date on which they expect the Vessel to be ready to load whereupon Charterers shall have the option to cancel this Charter…
24.… If after any loading or discharge port or place has been nominated Charterers desire to vary such port or place, Owners shall issue such revised instructions as are necessary at any time to give effect to Charterers’ revised orders and any period by which the steaming time taken to reach the alternative port or place exceeds the time which should have been taken had the Vessel proceeded thither directly shall count as laytime or, if the Vessel is on demurrage, as demurrage.”
The vessel proceeded to a nominated load port within the range provided for under the charterparty. The Charterers then nominated an alternative load port under clause 24. The Owners could not reach that load port by the cancellation date and the Charterers cancelled the charterparty in reliance upon clause 17. The Owners denied that the Charterers had a right to cancel and accepted the cancellation as a repudiation of the charterparty. The dispute went to arbitration.
The arbitration award
The Tribunal found in favour of the Owners and held that the cancellation provisions in clause 17 did not apply where the Charterers exercised the liberty given under clause 24 to re-nominate the load port. The Tribunal further held that, even if the cancellation provisions did apply, the Charterers may not cancel where the re-nomination was made at a time when the estimated time of arrival for the re-nominated port was after the cancellation date under the charterparty. The Charterers appealed to the Commercial Court.
The Commercial Court decision
When it came to construing the words in clauses 17 and 24 of the charterparty, the Court took as its starting point the ordinary and natural meaning of the words used in those clauses as they would be understood by reasonable charterers and owners in the context in which the agreement was made. The Court highlighted the importance of the fact that the parties to a charterparty were involved in a venture which required a degree of co-operation in order to work successfully. Regarding clause 17, the cancellation clause, the Charterers’ ability to cancel necessarily entailed that the Charterers would do what is necessary on their part to enable the vessel to achieve that cancellation date and not impair the
Owners’ ability to comply with that date
The Court also looked at the reasons why it is in the interests of both sides to agree a cancellation date. At common law, subject to the express terms of a charterparty, both parties are bound by the contract until the delay is such that it frustrates the commercial purpose of the venture. Agreeing a cancellation date provides certainty to both parties in that it avoids disputes as to when that delay has frustrated a contract, which is a matter of fact in each case.
The Court referred to the “broad commercial interpretation” it has previously taken in the construction of these types of clauses, in order to achieve the parties’ commercial objectives. In this regard, the Court examined the commercial considerations which underlie the re-nomination clause. For the Charterers, the main advantage of this clause is to have greater flexibility to revise their orders so as to tailor their shipping arrangements according to their cargo arrangements. On the other hand, absence of the load port re-nomination provision would be advantageous to the Owners since it would give them the certainty of an irrevocable nomination. The Court also noted the commercial value of the cancellation clause from the Charterers’ perspective. On balance, the Court placed more importance on the Owners’ concerns of losing the certainty of an irrevocable nomination, whilst at the same time remaining exposed to the Charterers’ right to cancel.
The Court also noted that clause 24 made no express reference to the cancellation rights under clause 17. The Court recognised that the BEEPEEVOY 3 charterparty, being a standard form, is a document drafted with considerable care. Had the draftsmen of this form intended for the clause 17 cancellation rights to apply to a re-nomination of the load port under clause 24, express words would have been used to that effect and would have provided for how such rights would apply and in what circumstances. No such words were present in this case.
The appeal was therefore dismissed.
Comment
This case serves as a useful reminder of the English Court’s approach to the interpretation of charterparty provisions and, in particular, to consideration of the interplay between a cancellation clause and a load port re-nomination provision under a voyage charterparty. This decision also highlights the Court’s commercial approach to such issues, in particular its reference to the Charterers’ duty to co-operate with the Owners and to do what is necessary to enable the vessel to achieve the cancellation date if they wish to be able to rely upon the cancellation clause.
Source: INCE&Co
If you believe an article violates your rights or the rights of others, please contact us.
|
|
Thursday, 29 April 10
KANGAROO RESOURCES INKS KEY COAL EXPORT CONTRACT WITH YUDEAN FARNON - PROACTIVE INVESTORS
Proactive Investors reprted that, Kangaroo Resources has secured an initial export sales contract for coal from the company’s operating coal p ...
Wednesday, 28 April 10
UNITED TRACTORS FOCUSES ON MINING AS IT SEEKS TO DIVERSIFY REVENUE SOURCES - JG
The Jakarta globe reported that, PT United Tractors, Indonesia’s biggest heavy-equipment distributor and mining contractor, aims to have its m ...
Wednesday, 28 April 10
DRY BULK MARKET
After a prolonged period of anticipation and a stalled dry bulk market in terms of freight rates, the industry’s benchmark, the Baltic Dry Ind ...
Tuesday, 27 April 10
CAPESIZES UP, PANAMAXES DOWN - BRS
It was Capesizes up, Panamaxes down this week as the latter experienced a correction after its recent gains. Period rates for Panamaxes remain firm ...
Tuesday, 27 April 10
S.KOREA EWP SEEKS 0.520 MILLION TONS OF SUB-BITUMINOUS COAL
COALspot.com: South Korea East West Power Company has called for term bids for supply of Sub-bituminous Coal for Dangjin Thermal Power Pla ...
|
|
|
Showing 5856 to 5860 news of total 6871 |
|
 |
|
|
|
|
| |
|
 |
|
|
| |
|
- Bahari Cakrawala Sebuku - Indonesia
- Power Finance Corporation Ltd., India
- Ministry of Mines - Canada
- Rio Tinto Coal - Australia
- Wilmar Investment Holdings
- Globalindo Alam Lestari - Indonesia
- Kepco SPC Power Corporation, Philippines
- Indonesian Coal Mining Association
- Directorate General of MIneral and Coal - Indonesia
- Leighton Contractors Pty Ltd - Australia
- Ambuja Cements Ltd - India
- Offshore Bulk Terminal Pte Ltd, Singapore
- Port Waratah Coal Services - Australia
- Australian Coal Association
- Filglen & Citicon Mining (HK) Ltd - Hong Kong
- Vijayanagar Sugar Pvt Ltd - India
- San Jose City I Power Corp, Philippines
- Bhushan Steel Limited - India
- Ministry of Finance - Indonesia
- Holcim Trading Pte Ltd - Singapore
- Petron Corporation, Philippines
- Metalloyd Limited - United Kingdom
- Dr Ramakrishna Prasad Power Pvt Ltd - India
- AsiaOL BioFuels Corp., Philippines
- Parliament of New Zealand
- LBH Netherlands Bv - Netherlands
- Mercator Lines Limited - India
- Renaissance Capital - South Africa
- Straits Asia Resources Limited - Singapore
- White Energy Company Limited
- Energy Development Corp, Philippines
- Minerals Council of Australia
- Siam City Cement - Thailand
- Jindal Steel & Power Ltd - India
- Intertek Mineral Services - Indonesia
- Dalmia Cement Bharat India
- Heidelberg Cement - Germany
- Kideco Jaya Agung - Indonesia
- SN Aboitiz Power Inc, Philippines
- New Zealand Coal & Carbon
- Electricity Generating Authority of Thailand
- Bukit Asam (Persero) Tbk - Indonesia
- Sakthi Sugars Limited - India
- Altura Mining Limited, Indonesia
- Kalimantan Lumbung Energi - Indonesia
- Barasentosa Lestari - Indonesia
- Borneo Indobara - Indonesia
- Global Coal Blending Company Limited - Australia
- Sree Jayajothi Cements Limited - India
- Bukit Baiduri Energy - Indonesia
- IHS Mccloskey Coal Group - USA
- European Bulk Services B.V. - Netherlands
- South Luzon Thermal Energy Corporation
- Singapore Mercantile Exchange
- Commonwealth Bank - Australia
- GN Power Mariveles Coal Plant, Philippines
- Energy Link Ltd, New Zealand
- Bukit Makmur.PT - Indonesia
- Kartika Selabumi Mining - Indonesia
- PTC India Limited - India
- Krishnapatnam Port Company Ltd. - India
- Siam City Cement PLC, Thailand
- Banpu Public Company Limited - Thailand
- Dong Bac Coal Mineral Investment Coporation - Vietnam
- CIMB Investment Bank - Malaysia
- Romanian Commodities Exchange
- CNBM International Corporation - China
- Sical Logistics Limited - India
- Bayan Resources Tbk. - Indonesia
- Grasim Industreis Ltd - India
- Riau Bara Harum - Indonesia
- Therma Luzon, Inc, Philippines
- Petrochimia International Co. Ltd.- Taiwan
- Coalindo Energy - Indonesia
- McConnell Dowell - Australia
- Meralco Power Generation, Philippines
- Attock Cement Pakistan Limited
- Chamber of Mines of South Africa
- Savvy Resources Ltd - HongKong
- Bhatia International Limited - India
- Kumho Petrochemical, South Korea
- Essar Steel Hazira Ltd - India
- Sindya Power Generating Company Private Ltd
- The State Trading Corporation of India Ltd
- TNB Fuel Sdn Bhd - Malaysia
- Eastern Energy - Thailand
- Chettinad Cement Corporation Ltd - India
- Global Business Power Corporation, Philippines
- MS Steel International - UAE
- Vedanta Resources Plc - India
- Thai Mozambique Logistica
- Alfred C Toepfer International GmbH - Germany
- Cement Manufacturers Association - India
- GAC Shipping (India) Pvt Ltd
- Indo Tambangraya Megah - Indonesia
- The Treasury - Australian Government
- TeaM Sual Corporation - Philippines
- Aditya Birla Group - India
- Billiton Holdings Pty Ltd - Australia
- GVK Power & Infra Limited - India
- Global Green Power PLC Corporation, Philippines
- International Coal Ventures Pvt Ltd - India
- SMG Consultants - Indonesia
- Miang Besar Coal Terminal - Indonesia
- Directorate Of Revenue Intelligence - India
- Price Waterhouse Coopers - Russia
- Uttam Galva Steels Limited - India
- Cigading International Bulk Terminal - Indonesia
- Kaltim Prima Coal - Indonesia
- Binh Thuan Hamico - Vietnam
- Meenaskhi Energy Private Limited - India
- Bulk Trading Sa - Switzerland
- Larsen & Toubro Limited - India
- Planning Commission, India
- Kohat Cement Company Ltd. - Pakistan
- Goldman Sachs - Singapore
- Bank of Tokyo Mitsubishi UFJ Ltd
- Thiess Contractors Indonesia
- Electricity Authority, New Zealand
- Indogreen Group - Indonesia
- Formosa Plastics Group - Taiwan
- Star Paper Mills Limited - India
- PNOC Exploration Corporation - Philippines
- Videocon Industries ltd - India
- Sinarmas Energy and Mining - Indonesia
- OPG Power Generation Pvt Ltd - India
- Samtan Co., Ltd - South Korea
- Timah Investasi Mineral - Indoneisa
- ASAPP Information Group - India
- Australian Commodity Traders Exchange
- Mercuria Energy - Indonesia
- Neyveli Lignite Corporation Ltd, - India
- Mjunction Services Limited - India
- Bhoruka Overseas - Indonesia
- Sarangani Energy Corporation, Philippines
- Bangladesh Power Developement Board
- Maharashtra Electricity Regulatory Commission - India
- Rashtriya Ispat Nigam Limited - India
- Vizag Seaport Private Limited - India
- Sojitz Corporation - Japan
- Merrill Lynch Commodities Europe
- Medco Energi Mining Internasional
- Africa Commodities Group - South Africa
- Truba Alam Manunggal Engineering.Tbk - Indonesia
- Marubeni Corporation - India
- Semirara Mining and Power Corporation, Philippines
- Jaiprakash Power Ventures ltd
- Economic Council, Georgia
- VISA Power Limited - India
- Indika Energy - Indonesia
- Coastal Gujarat Power Limited - India
- Gujarat Electricity Regulatory Commission - India
- SMC Global Power, Philippines
- Bharathi Cement Corporation - India
- Iligan Light & Power Inc, Philippines
- Georgia Ports Authority, United States
- PowerSource Philippines DevCo
- ICICI Bank Limited - India
- Indian Oil Corporation Limited
- India Bulls Power Limited - India
- Eastern Coal Council - USA
- Anglo American - United Kingdom
- The University of Queensland
- Oldendorff Carriers - Singapore
- Edison Trading Spa - Italy
- Trasteel International SA, Italy
- IEA Clean Coal Centre - UK
- Jorong Barutama Greston.PT - Indonesia
- Gujarat Mineral Development Corp Ltd - India
- Madhucon Powers Ltd - India
- Central Java Power - Indonesia
- Karbindo Abesyapradhi - Indoneisa
- Orica Australia Pty. Ltd.
- London Commodity Brokers - England
- Central Electricity Authority - India
- Lanco Infratech Ltd - India
- Antam Resourcindo - Indonesia
- Semirara Mining Corp, Philippines
- Simpson Spence & Young - Indonesia
- Kobexindo Tractors - Indoneisa
- Interocean Group of Companies - India
- Ind-Barath Power Infra Limited - India
- Kapuas Tunggal Persada - Indonesia
- Coal and Oil Company - UAE
- Pendopo Energi Batubara - Indonesia
- Karaikal Port Pvt Ltd - India
- Tamil Nadu electricity Board
- Ceylon Electricity Board - Sri Lanka
- Carbofer General Trading SA - India
- Independent Power Producers Association of India
- Ministry of Transport, Egypt
- Manunggal Multi Energi - Indonesia
- Wood Mackenzie - Singapore
- Maheswari Brothers Coal Limited - India
- Standard Chartered Bank - UAE
- Orica Mining Services - Indonesia
- GMR Energy Limited - India
- Posco Energy - South Korea
- Indian Energy Exchange, India
- Pipit Mutiara Jaya. PT, Indonesia
- Asia Pacific Energy Resources Ventures Inc, Philippines
- PetroVietnam Power Coal Import and Supply Company
- Mintek Dendrill Indonesia
- Makarim & Taira - Indonesia
- Aboitiz Power Corporation - Philippines
- Salva Resources Pvt Ltd - India
- Baramulti Group, Indonesia
- Tata Chemicals Ltd - India
- Malabar Cements Ltd - India
- Deloitte Consulting - India
- Toyota Tsusho Corporation, Japan
- Parry Sugars Refinery, India
- Latin American Coal - Colombia
- Gujarat Sidhee Cement - India
- Agrawal Coal Company - India
- Xindia Steels Limited - India
- Asmin Koalindo Tuhup - Indonesia
|
| |
| |
|
