We welcome article submissions from experts in the areas of coal, mining,
shipping, etc.
To Submit your article please click here.
|
|
|
Friday, 17 July 15
DO CANCELLATION RIGHTS UNDER VOYAGE CHARTERPARTY SURVIVE RE-NOMINATION OF LOAD PORT? - INCE&CO
 KNOWLEDGE TO ELEVATE
Do cancellation rights under voyage charterparty survive re-nomination of load port?
St Shipping & Transport Inc v. Kriti Filoxenia Shipping Co SA [2015] EWHC 997 (Comm) (MT Kriti Filoxenia)
The Commercial Court has considered whether cancellation provisions in the BEEPEEVOY3 charterparty form were applicable in the event of re-nomination of a load port by charterers under the charter. In this case, the Charterers re-nominated the load port which the Owners were not able to reach by the cancellation date. The Charterers cancelled the charterparty. In arbitration proceedings, the Tribunal found that the cancellation provisions were not applicable where the Charterers had exercised the contractual option to re-nominate a load port. The Charterers appealed the decision to the Commercial Court, which upheld the findings of the Tribunal and dismissed the appeal.
The background facts
This case concerned a voyage charterparty under the BEEPEEVOY 3 standard form. The key clauses in the charterparty provided as follows:
“17.… If it appears to Charterers that the Vessel will be delayed beyond the Cancelling Date Charterers may require Owners to notify Charterers of the date on which they expect the Vessel to be ready to load whereupon Charterers shall have the option to cancel this Charter…
24.… If after any loading or discharge port or place has been nominated Charterers desire to vary such port or place, Owners shall issue such revised instructions as are necessary at any time to give effect to Charterers’ revised orders and any period by which the steaming time taken to reach the alternative port or place exceeds the time which should have been taken had the Vessel proceeded thither directly shall count as laytime or, if the Vessel is on demurrage, as demurrage.”
The vessel proceeded to a nominated load port within the range provided for under the charterparty. The Charterers then nominated an alternative load port under clause 24. The Owners could not reach that load port by the cancellation date and the Charterers cancelled the charterparty in reliance upon clause 17. The Owners denied that the Charterers had a right to cancel and accepted the cancellation as a repudiation of the charterparty. The dispute went to arbitration.
The arbitration award
The Tribunal found in favour of the Owners and held that the cancellation provisions in clause 17 did not apply where the Charterers exercised the liberty given under clause 24 to re-nominate the load port. The Tribunal further held that, even if the cancellation provisions did apply, the Charterers may not cancel where the re-nomination was made at a time when the estimated time of arrival for the re-nominated port was after the cancellation date under the charterparty. The Charterers appealed to the Commercial Court.
The Commercial Court decision
When it came to construing the words in clauses 17 and 24 of the charterparty, the Court took as its starting point the ordinary and natural meaning of the words used in those clauses as they would be understood by reasonable charterers and owners in the context in which the agreement was made. The Court highlighted the importance of the fact that the parties to a charterparty were involved in a venture which required a degree of co-operation in order to work successfully. Regarding clause 17, the cancellation clause, the Charterers’ ability to cancel necessarily entailed that the Charterers would do what is necessary on their part to enable the vessel to achieve that cancellation date and not impair the
Owners’ ability to comply with that date
The Court also looked at the reasons why it is in the interests of both sides to agree a cancellation date. At common law, subject to the express terms of a charterparty, both parties are bound by the contract until the delay is such that it frustrates the commercial purpose of the venture. Agreeing a cancellation date provides certainty to both parties in that it avoids disputes as to when that delay has frustrated a contract, which is a matter of fact in each case.
The Court referred to the “broad commercial interpretation” it has previously taken in the construction of these types of clauses, in order to achieve the parties’ commercial objectives. In this regard, the Court examined the commercial considerations which underlie the re-nomination clause. For the Charterers, the main advantage of this clause is to have greater flexibility to revise their orders so as to tailor their shipping arrangements according to their cargo arrangements. On the other hand, absence of the load port re-nomination provision would be advantageous to the Owners since it would give them the certainty of an irrevocable nomination. The Court also noted the commercial value of the cancellation clause from the Charterers’ perspective. On balance, the Court placed more importance on the Owners’ concerns of losing the certainty of an irrevocable nomination, whilst at the same time remaining exposed to the Charterers’ right to cancel.
The Court also noted that clause 24 made no express reference to the cancellation rights under clause 17. The Court recognised that the BEEPEEVOY 3 charterparty, being a standard form, is a document drafted with considerable care. Had the draftsmen of this form intended for the clause 17 cancellation rights to apply to a re-nomination of the load port under clause 24, express words would have been used to that effect and would have provided for how such rights would apply and in what circumstances. No such words were present in this case.
The appeal was therefore dismissed.
Comment
This case serves as a useful reminder of the English Court’s approach to the interpretation of charterparty provisions and, in particular, to consideration of the interplay between a cancellation clause and a load port re-nomination provision under a voyage charterparty. This decision also highlights the Court’s commercial approach to such issues, in particular its reference to the Charterers’ duty to co-operate with the Owners and to do what is necessary to enable the vessel to achieve the cancellation date if they wish to be able to rely upon the cancellation clause.
Source: INCE&Co
If you believe an article violates your rights or the rights of others, please contact us.
|
|
Thursday, 22 December 11
DRY BULK MARKET KEEPS LOSING TRACTION AHEAD OF HOLIDAY SEASON - NIKOS ROUSSANOGLOU, HELLENIC SHIPPING
The dry bulk market kept retreating in the middle of the week, as charterers seem to be looking towards the holiday season and the start of the new ye ...
Tuesday, 20 December 11
THE COAL IMPORT INTO CHINA WAS QUIETER AS COAL STOCKS WERE AT HIGH LEVELS - BRS
The BDI ended the week at 1888 points (-1.8%), the BCI corrected to 3572 (-3.4%), the BPI was up at 1,775 (+3.6%), the BSI dropped to 1193 (-3.0%) a ...
Tuesday, 20 December 11
INDIA IMPORTS 66.41 PERCENT MORE COAL FROM INDONESIA LAST MONTH - SOURCES
COALspot.com: Indonesia, the world largest coal exporter, shipped 33.476* mln mt of coal in November, which is slightly higher than its Octobe ...
Monday, 19 December 11
KOPEX COMMITS ADDITIONAL ONE MILLION DOLLAR FOR PT TRANSCOAL MINERGY
COALspot.com - Mining contractor Kopex has agreed to extend a further US$1 million to finance the remainder of the expanded drill program at PT Tran ...
Monday, 19 December 11
PLN WILL NO LONGER BUY COAL FROM TRADERS
COALspot.com - Indonesia's state electricity company PT Perusahaan Listrik Negara will no longer allow traders to become their suppliers, said, its ...
|
|
|
Showing 4921 to 4925 news of total 6871 |
|
 |
|
|
|
|
| |
|
 |
|
|
| |
|
- Electricity Authority, New Zealand
- Medco Energi Mining Internasional
- Altura Mining Limited, Indonesia
- Eastern Coal Council - USA
- Karbindo Abesyapradhi - Indoneisa
- Marubeni Corporation - India
- Rio Tinto Coal - Australia
- Chamber of Mines of South Africa
- Sical Logistics Limited - India
- Samtan Co., Ltd - South Korea
- Coastal Gujarat Power Limited - India
- Agrawal Coal Company - India
- Grasim Industreis Ltd - India
- Romanian Commodities Exchange
- Parry Sugars Refinery, India
- Formosa Plastics Group - Taiwan
- Neyveli Lignite Corporation Ltd, - India
- San Jose City I Power Corp, Philippines
- Ind-Barath Power Infra Limited - India
- SMC Global Power, Philippines
- Electricity Generating Authority of Thailand
- SMG Consultants - Indonesia
- Standard Chartered Bank - UAE
- Aditya Birla Group - India
- Indogreen Group - Indonesia
- Georgia Ports Authority, United States
- Maheswari Brothers Coal Limited - India
- Kalimantan Lumbung Energi - Indonesia
- Directorate Of Revenue Intelligence - India
- GMR Energy Limited - India
- Thiess Contractors Indonesia
- Dr Ramakrishna Prasad Power Pvt Ltd - India
- Vijayanagar Sugar Pvt Ltd - India
- GN Power Mariveles Coal Plant, Philippines
- PNOC Exploration Corporation - Philippines
- New Zealand Coal & Carbon
- Price Waterhouse Coopers - Russia
- Toyota Tsusho Corporation, Japan
- Central Java Power - Indonesia
- Indo Tambangraya Megah - Indonesia
- Indika Energy - Indonesia
- Maharashtra Electricity Regulatory Commission - India
- Singapore Mercantile Exchange
- PetroVietnam Power Coal Import and Supply Company
- Merrill Lynch Commodities Europe
- Asia Pacific Energy Resources Ventures Inc, Philippines
- Posco Energy - South Korea
- Sakthi Sugars Limited - India
- LBH Netherlands Bv - Netherlands
- Simpson Spence & Young - Indonesia
- Bulk Trading Sa - Switzerland
- Jorong Barutama Greston.PT - Indonesia
- Kideco Jaya Agung - Indonesia
- Jaiprakash Power Ventures ltd
- Intertek Mineral Services - Indonesia
- MS Steel International - UAE
- Carbofer General Trading SA - India
- Africa Commodities Group - South Africa
- Energy Development Corp, Philippines
- Malabar Cements Ltd - India
- Semirara Mining and Power Corporation, Philippines
- Bank of Tokyo Mitsubishi UFJ Ltd
- The University of Queensland
- Ministry of Transport, Egypt
- TNB Fuel Sdn Bhd - Malaysia
- London Commodity Brokers - England
- Indian Energy Exchange, India
- Globalindo Alam Lestari - Indonesia
- PTC India Limited - India
- Bukit Baiduri Energy - Indonesia
- Eastern Energy - Thailand
- PowerSource Philippines DevCo
- Siam City Cement - Thailand
- Miang Besar Coal Terminal - Indonesia
- Thai Mozambique Logistica
- Oldendorff Carriers - Singapore
- Planning Commission, India
- Makarim & Taira - Indonesia
- Sree Jayajothi Cements Limited - India
- Gujarat Electricity Regulatory Commission - India
- Holcim Trading Pte Ltd - Singapore
- Billiton Holdings Pty Ltd - Australia
- The Treasury - Australian Government
- India Bulls Power Limited - India
- IHS Mccloskey Coal Group - USA
- Meenaskhi Energy Private Limited - India
- Mjunction Services Limited - India
- Aboitiz Power Corporation - Philippines
- Ministry of Mines - Canada
- Global Business Power Corporation, Philippines
- Mintek Dendrill Indonesia
- Kumho Petrochemical, South Korea
- Rashtriya Ispat Nigam Limited - India
- Banpu Public Company Limited - Thailand
- International Coal Ventures Pvt Ltd - India
- Sindya Power Generating Company Private Ltd
- Therma Luzon, Inc, Philippines
- Parliament of New Zealand
- Barasentosa Lestari - Indonesia
- Ceylon Electricity Board - Sri Lanka
- IEA Clean Coal Centre - UK
- Vedanta Resources Plc - India
- Kohat Cement Company Ltd. - Pakistan
- Straits Asia Resources Limited - Singapore
- Bukit Asam (Persero) Tbk - Indonesia
- Ambuja Cements Ltd - India
- Bhoruka Overseas - Indonesia
- Karaikal Port Pvt Ltd - India
- Latin American Coal - Colombia
- Ministry of Finance - Indonesia
- VISA Power Limited - India
- ICICI Bank Limited - India
- Indian Oil Corporation Limited
- Coalindo Energy - Indonesia
- Alfred C Toepfer International GmbH - Germany
- Kobexindo Tractors - Indoneisa
- Coal and Oil Company - UAE
- Manunggal Multi Energi - Indonesia
- Port Waratah Coal Services - Australia
- Riau Bara Harum - Indonesia
- Gujarat Sidhee Cement - India
- Gujarat Mineral Development Corp Ltd - India
- Orica Mining Services - Indonesia
- Pendopo Energi Batubara - Indonesia
- Larsen & Toubro Limited - India
- Minerals Council of Australia
- Vizag Seaport Private Limited - India
- Deloitte Consulting - India
- Iligan Light & Power Inc, Philippines
- GAC Shipping (India) Pvt Ltd
- Renaissance Capital - South Africa
- Offshore Bulk Terminal Pte Ltd, Singapore
- Economic Council, Georgia
- Mercuria Energy - Indonesia
- Essar Steel Hazira Ltd - India
- Attock Cement Pakistan Limited
- Chettinad Cement Corporation Ltd - India
- Salva Resources Pvt Ltd - India
- Petrochimia International Co. Ltd.- Taiwan
- Bahari Cakrawala Sebuku - Indonesia
- Leighton Contractors Pty Ltd - Australia
- McConnell Dowell - Australia
- Edison Trading Spa - Italy
- Global Coal Blending Company Limited - Australia
- White Energy Company Limited
- CIMB Investment Bank - Malaysia
- Trasteel International SA, Italy
- South Luzon Thermal Energy Corporation
- The State Trading Corporation of India Ltd
- Baramulti Group, Indonesia
- Jindal Steel & Power Ltd - India
- SN Aboitiz Power Inc, Philippines
- Krishnapatnam Port Company Ltd. - India
- Semirara Mining Corp, Philippines
- TeaM Sual Corporation - Philippines
- Bharathi Cement Corporation - India
- Asmin Koalindo Tuhup - Indonesia
- Heidelberg Cement - Germany
- Pipit Mutiara Jaya. PT, Indonesia
- European Bulk Services B.V. - Netherlands
- Kartika Selabumi Mining - Indonesia
- Bhushan Steel Limited - India
- ASAPP Information Group - India
- Dong Bac Coal Mineral Investment Coporation - Vietnam
- Meralco Power Generation, Philippines
- Bangladesh Power Developement Board
- Tamil Nadu electricity Board
- Energy Link Ltd, New Zealand
- Borneo Indobara - Indonesia
- Savvy Resources Ltd - HongKong
- Wood Mackenzie - Singapore
- OPG Power Generation Pvt Ltd - India
- Metalloyd Limited - United Kingdom
- Tata Chemicals Ltd - India
- Uttam Galva Steels Limited - India
- Commonwealth Bank - Australia
- Kapuas Tunggal Persada - Indonesia
- Global Green Power PLC Corporation, Philippines
- Interocean Group of Companies - India
- Siam City Cement PLC, Thailand
- Indonesian Coal Mining Association
- CNBM International Corporation - China
- Power Finance Corporation Ltd., India
- Lanco Infratech Ltd - India
- Filglen & Citicon Mining (HK) Ltd - Hong Kong
- Truba Alam Manunggal Engineering.Tbk - Indonesia
- Wilmar Investment Holdings
- Cement Manufacturers Association - India
- Independent Power Producers Association of India
- Kaltim Prima Coal - Indonesia
- Binh Thuan Hamico - Vietnam
- Central Electricity Authority - India
- Madhucon Powers Ltd - India
- Sarangani Energy Corporation, Philippines
- Australian Commodity Traders Exchange
- Dalmia Cement Bharat India
- Cigading International Bulk Terminal - Indonesia
- AsiaOL BioFuels Corp., Philippines
- Sojitz Corporation - Japan
- Bhatia International Limited - India
- Mercator Lines Limited - India
- Anglo American - United Kingdom
- Antam Resourcindo - Indonesia
- Australian Coal Association
- GVK Power & Infra Limited - India
- Goldman Sachs - Singapore
- Orica Australia Pty. Ltd.
- Bukit Makmur.PT - Indonesia
- Kepco SPC Power Corporation, Philippines
- Petron Corporation, Philippines
- Sinarmas Energy and Mining - Indonesia
- Xindia Steels Limited - India
- Timah Investasi Mineral - Indoneisa
- Star Paper Mills Limited - India
- Directorate General of MIneral and Coal - Indonesia
- Videocon Industries ltd - India
- Bayan Resources Tbk. - Indonesia
|
| |
| |
|
